DAVIDYEK
  • Home
  • About
    • Professional Registration
    • Qualifications
    • Engagements
    • Private Practice
    • SIF Fellows
  • Practice
    • Our Approach >
      • S:Scale [Artefacts]
      • M:Scale [Building]
      • L:Scale [Urban]
    • Large Projects >
      • Highrises >
        • SSM International School
        • JBio
        • UKIH
        • Vertigo Residency
        • Diorama
        • Resi-Hub
        • SunMed
        • Medini
        • Palmspring Damansara
        • Blink
      • Lowrises >
        • Data Center
        • Garden Homes
        • XIN
        • Albient
        • Hillcourt
    • Small Projects >
      • Rustic Raphsody
      • MCM >
        • Estate House
        • Uniform Annex
        • Kitchen Extension
        • Sixth Form Center
      • Putrajaya Boulevard >
        • LOO
        • BOO
        • DOO
        • 5 Elements Tower
      • Detached Houses >
        • Batu Residence
        • Malaqa Residence
        • ParkCity Residence
        • Sierramas Residence
      • Commercial >
        • Albion Club
        • QuanYuan
        • Nippon Go
    • Interior Designs >
      • Spartan Minimalism
      • Neo Retro
      • Reflective Modern
    • UBBL 1984
    • Newsletter
  • DYA + C
    • Our CV
    • Adjudication >
      • CIPAA Procedure >
        • Scope of CIPAA
    • Arbitration >
      • Appointment of Arbitrator >
        • Terms of Appointment >
          • Preliminary Meeting Agenda
      • PAM Arbitration Procedure
      • Arbitration Costs Breakdowns >
        • Drawdown
      • Award Writing Blog >
        • Expert Evidence in Arbitration
    • Mediation >
      • Appointment of Mediator
      • Mediation Process
      • Skill Set Lev 01 & 02
    • Expert Determination >
      • Expert Rules - PAM
      • Expert Determination Processes
    • Building Inspection Services
    • Courses & Training >
      • Contract Administration
    • ADR & Construction Law
  • Consultant
    • QuanYuan 泉緣 Story
    • Review
    • QuanYuan >
      • Why QuanYuan?
      • Modus Operandi
      • Consultancy Services
    • Our Lineage
    • Workshop >
      • Teacher's Profiles
      • Message
      • SanYuan 01 - Introduction
      • Community
      • Registration of Interest
    • QiMen DunJia 奇門遁甲 >
      • QMDJ - Shifting Palace
    • Audit & Cases >
      • Cases - REA Hotel
      • Cases - Childless Couple
      • Cases - Childless Couple 02
    • Yifengshui
    • Newsletter >
      • MBS FengShui Reinvestigated
    • FAQ
    • E-Store
  • Educator
    • Author I am...
    • Speaking Engagement >
      • Arch Edu Practice Paper - 3Ds Pedagogy
    • Journey in USM(Arch) >
      • Thesis >
        • Site Analysis
        • Urban Design Approach
        • Sketch Design
        • Model Based Paradigm
        • Technical Studies
      • Studio 01
      • Studio 02
    • Discourse in Studio 6 >
      • Ideation
      • The Production Model >
        • The Actors
        • The Stage
        • Urban Mass
        • The Box
        • The Play
        • The Break
        • The Newsletter
        • The Document
        • The Presentation
    • d:KON 4 >
      • Actors >
        • Chua LiCheng
        • Ng KenHong
        • Sean Tan
        • Peggy Chai
        • Elliotte Teoh
        • Vincent Tow
        • TzeLer
        • Elaine
        • Ng SongChun
        • Carissa Foong
        • Ng WeiMun
        • Ng ChenYin
        • Nicol Ong
        • Adron Liang
        • Ivan Sung
        • Lau HuiJew
      • Acts >
        • Portraiture
        • A Slice of Space Time
        • Box of Installation of Lights
        • Radio Misreading
        • Grid of Destinies
        • Shelter
        • Anatomy of Pain
        • Tensigrity of Ego
        • Of Prisons and Walls
        • Forest of Nails
        • Curtain of Fears
        • Dissolution of the Ego
        • If it's Ain't Broken it's Ain't Worth Mending
        • Flight of Freedom
        • Cross of Complexity and Contradiction
        • interrogation
      • Stage >
        • Soap Box
      • Play
      • Approach
      • Galleria >
        • Martial Gallery
        • Drive Through Gallery
        • Clinique Gallery
        • Cafe Gallery
        • MACC Gallery
        • Haunted Gallery
        • Backpacker Hotel
        • Audio Bookshop Gallery
        • Funeral Parlour
        • Extreme Game Gallery
        • Play Ground
        • Wedding Gallery
        • Meditation Gallery
        • Water Tower
        • Photography Studio
        • Chapel Gallery
    • External Critique >
      • Discourse in Sem 06
      • Discourse in Sem 05 >
        • The Site - KB
        • The Rectilinear
        • The Paired Kidneys
        • The Boat
        • The Decepticon
        • The Curvature
      • EnviroDesign MasterClass 2015
    • Philosophy
    • Codes Regulations & Standards >
      • Building Codes
      • Fire Codes
      • QAQC & Building Inspection
      • Critics
  • Photo Essays
    • Shanghai
    • Siemreap
  • Contact

BDG CONTRACT 101 - CL27.8

5/25/2014

0 Comments

 
Picture
Question:

You are an Architect for Project ABC. The Contractor CDE has delayed. The Contract Period has another 6 months to go. The Contractor is blaming its NSC of non-performance and herewith request you as the Architect for consent to terminate the NSC under PAM2006. What will be your response?

Answer:

1.       One of the method employed by Contractor for mandatory EOT is to determine the NSC almost to the tail end of the Project.

2.       The PAM98 form does not require consent for NSC determination. However, in the PAM2006 form Cl27.8 require the Architect’s written consent as a precedent condition for NSC determination.

3.       Here is the catch, if the Architect consented, the Contractor is automatically granted for additional EOT as time is required to re-nominate. If the Architect decline, the Contractor may accused the Architect for unreasonably withholding consent.

4.       To avoid being unreasonable, the burden of proof rests upon the Contractor to present. Such proof has to be beyond reasonable doubt. The benefit of the doubt must rest within the NSC. Cl27.8 implied the Architect to be in due diligent to the NSC.

5.       In the event that the proofs are insufficient, the Architect has the right to withhold consent until further notice. There is no specific time for the Architect to give consent. 


0 Comments

Your comment will be posted after it is approved.


Leave a Reply.

    David Yek Tak Wai

    Create Your Badge

    Archives

    January 2021
    December 2019
    November 2016
    January 2015
    December 2014
    November 2014
    October 2014
    August 2014
    June 2014
    May 2014


    Categories

    All
    Architecture
    Bandung
    Board Of Architect Malaysia
    Box
    Building Contract
    Business
    Business Development
    Chinese Architecture
    CIDB
    Construction Law
    Eco City
    Essays
    Geomancy
    HDA
    Highrise
    Indonesia
    Judiciary
    KanYu
    Law
    Local Authority
    Malaysia
    Malaysian Pavilion
    Management Theory
    Marketing
    Mega Project
    Minimum Fee Rule
    Occupational Safety & Health In Construction Industry Management
    OSHCIM
    PAM2006
    Phenomenology
    Politics
    Power Of Courts
    Practice Forum
    Production Model
    Provocateur
    SiHeYuan 四合院
    Singapore
    Socio Religion
    Socio-religion
    Theory
    Tourism Board
    UBBL
    UM
    Urban Design
    UTM
    World Expo
    Xin


    RSS Feed


Powered by Create your own unique website with customizable templates.
  • Home
  • About
    • Professional Registration
    • Qualifications
    • Engagements
    • Private Practice
    • SIF Fellows
  • Practice
    • Our Approach >
      • S:Scale [Artefacts]
      • M:Scale [Building]
      • L:Scale [Urban]
    • Large Projects >
      • Highrises >
        • SSM International School
        • JBio
        • UKIH
        • Vertigo Residency
        • Diorama
        • Resi-Hub
        • SunMed
        • Medini
        • Palmspring Damansara
        • Blink
      • Lowrises >
        • Data Center
        • Garden Homes
        • XIN
        • Albient
        • Hillcourt
    • Small Projects >
      • Rustic Raphsody
      • MCM >
        • Estate House
        • Uniform Annex
        • Kitchen Extension
        • Sixth Form Center
      • Putrajaya Boulevard >
        • LOO
        • BOO
        • DOO
        • 5 Elements Tower
      • Detached Houses >
        • Batu Residence
        • Malaqa Residence
        • ParkCity Residence
        • Sierramas Residence
      • Commercial >
        • Albion Club
        • QuanYuan
        • Nippon Go
    • Interior Designs >
      • Spartan Minimalism
      • Neo Retro
      • Reflective Modern
    • UBBL 1984
    • Newsletter
  • DYA + C
    • Our CV
    • Adjudication >
      • CIPAA Procedure >
        • Scope of CIPAA
    • Arbitration >
      • Appointment of Arbitrator >
        • Terms of Appointment >
          • Preliminary Meeting Agenda
      • PAM Arbitration Procedure
      • Arbitration Costs Breakdowns >
        • Drawdown
      • Award Writing Blog >
        • Expert Evidence in Arbitration
    • Mediation >
      • Appointment of Mediator
      • Mediation Process
      • Skill Set Lev 01 & 02
    • Expert Determination >
      • Expert Rules - PAM
      • Expert Determination Processes
    • Building Inspection Services
    • Courses & Training >
      • Contract Administration
    • ADR & Construction Law
  • Consultant
    • QuanYuan 泉緣 Story
    • Review
    • QuanYuan >
      • Why QuanYuan?
      • Modus Operandi
      • Consultancy Services
    • Our Lineage
    • Workshop >
      • Teacher's Profiles
      • Message
      • SanYuan 01 - Introduction
      • Community
      • Registration of Interest
    • QiMen DunJia 奇門遁甲 >
      • QMDJ - Shifting Palace
    • Audit & Cases >
      • Cases - REA Hotel
      • Cases - Childless Couple
      • Cases - Childless Couple 02
    • Yifengshui
    • Newsletter >
      • MBS FengShui Reinvestigated
    • FAQ
    • E-Store
  • Educator
    • Author I am...
    • Speaking Engagement >
      • Arch Edu Practice Paper - 3Ds Pedagogy
    • Journey in USM(Arch) >
      • Thesis >
        • Site Analysis
        • Urban Design Approach
        • Sketch Design
        • Model Based Paradigm
        • Technical Studies
      • Studio 01
      • Studio 02
    • Discourse in Studio 6 >
      • Ideation
      • The Production Model >
        • The Actors
        • The Stage
        • Urban Mass
        • The Box
        • The Play
        • The Break
        • The Newsletter
        • The Document
        • The Presentation
    • d:KON 4 >
      • Actors >
        • Chua LiCheng
        • Ng KenHong
        • Sean Tan
        • Peggy Chai
        • Elliotte Teoh
        • Vincent Tow
        • TzeLer
        • Elaine
        • Ng SongChun
        • Carissa Foong
        • Ng WeiMun
        • Ng ChenYin
        • Nicol Ong
        • Adron Liang
        • Ivan Sung
        • Lau HuiJew
      • Acts >
        • Portraiture
        • A Slice of Space Time
        • Box of Installation of Lights
        • Radio Misreading
        • Grid of Destinies
        • Shelter
        • Anatomy of Pain
        • Tensigrity of Ego
        • Of Prisons and Walls
        • Forest of Nails
        • Curtain of Fears
        • Dissolution of the Ego
        • If it's Ain't Broken it's Ain't Worth Mending
        • Flight of Freedom
        • Cross of Complexity and Contradiction
        • interrogation
      • Stage >
        • Soap Box
      • Play
      • Approach
      • Galleria >
        • Martial Gallery
        • Drive Through Gallery
        • Clinique Gallery
        • Cafe Gallery
        • MACC Gallery
        • Haunted Gallery
        • Backpacker Hotel
        • Audio Bookshop Gallery
        • Funeral Parlour
        • Extreme Game Gallery
        • Play Ground
        • Wedding Gallery
        • Meditation Gallery
        • Water Tower
        • Photography Studio
        • Chapel Gallery
    • External Critique >
      • Discourse in Sem 06
      • Discourse in Sem 05 >
        • The Site - KB
        • The Rectilinear
        • The Paired Kidneys
        • The Boat
        • The Decepticon
        • The Curvature
      • EnviroDesign MasterClass 2015
    • Philosophy
    • Codes Regulations & Standards >
      • Building Codes
      • Fire Codes
      • QAQC & Building Inspection
      • Critics
  • Photo Essays
    • Shanghai
    • Siemreap
  • Contact