DAVIDYEK
  • Home
  • About
    • Professional Registration
    • Qualifications
    • Engagements
    • Private Practice
    • SIF Fellows
  • Practice
    • Our Approach >
      • S:Scale [Artefacts]
      • M:Scale [Building]
      • L:Scale [Urban]
    • Large Projects >
      • Highrises >
        • SSM International School
        • JBio
        • UKIH
        • Vertigo Residency
        • Diorama
        • Resi-Hub
        • SunMed
        • Medini
        • Palmspring Damansara
        • Blink
      • Lowrises >
        • Data Center
        • Garden Homes
        • XIN
        • Albient
        • Hillcourt
    • Small Projects >
      • Rustic Raphsody
      • MCM >
        • Estate House
        • Uniform Annex
        • Kitchen Extension
        • Sixth Form Center
      • Putrajaya Boulevard >
        • LOO
        • BOO
        • DOO
        • 5 Elements Tower
      • Detached Houses >
        • Batu Residence
        • Malaqa Residence
        • ParkCity Residence
        • Sierramas Residence
      • Commercial >
        • Albion Club
        • QuanYuan
        • Nippon Go
    • Interior Designs >
      • Spartan Minimalism
      • Neo Retro
      • Reflective Modern
    • UBBL 1984
    • Newsletter
  • DYA + C
    • Our CV
    • Adjudication >
      • CIPAA Procedure >
        • Scope of CIPAA
    • Arbitration >
      • Appointment of Arbitrator >
        • Terms of Appointment >
          • Preliminary Meeting Agenda
      • PAM Arbitration Procedure
      • Arbitration Costs Breakdowns >
        • Drawdown
      • Award Writing Blog >
        • Expert Evidence in Arbitration
    • Mediation >
      • Appointment of Mediator
      • Mediation Process
      • Skill Set Lev 01 & 02
    • Expert Determination >
      • Expert Rules - PAM
      • Expert Determination Processes
    • Building Inspection Services
    • Courses & Training >
      • Contract Administration
    • ADR & Construction Law
  • Consultant
    • QuanYuan 泉緣 Story
    • Review
    • QuanYuan >
      • Why QuanYuan?
      • Modus Operandi
      • Consultancy Services
    • Our Lineage
    • Workshop >
      • Teacher's Profiles
      • Message
      • SanYuan 01 - Introduction
      • Community
      • Registration of Interest
    • QiMen DunJia 奇門遁甲 >
      • QMDJ - Shifting Palace
    • Audit & Cases >
      • Cases - REA Hotel
      • Cases - Childless Couple
      • Cases - Childless Couple 02
    • Yifengshui
    • Newsletter >
      • MBS FengShui Reinvestigated
    • FAQ
    • E-Store
  • Educator
    • Author I am...
    • Speaking Engagement >
      • International Contract
      • PAM cpd UNLIMITED 2.0
      • Arch Edu Practice Paper - 3Ds Pedagogy
    • Attempting Law School
    • Journey in USM(Arch) >
      • Thesis >
        • Site Analysis
        • Urban Design Approach
        • Sketch Design
        • Model Based Paradigm
        • Technical Studies
      • Studio 01
      • Studio 02
    • Discourse in Studio 6 >
      • Ideation
      • The Production Model >
        • The Actors
        • The Stage
        • Urban Mass
        • The Box
        • The Play
        • The Break
        • The Newsletter
        • The Document
        • The Presentation
    • d:KON 4 >
      • Actors >
        • Chua LiCheng
        • Ng KenHong
        • Sean Tan
        • Peggy Chai
        • Elliotte Teoh
        • Vincent Tow
        • TzeLer
        • Elaine
        • Ng SongChun
        • Carissa Foong
        • Ng WeiMun
        • Ng ChenYin
        • Nicol Ong
        • Adron Liang
        • Ivan Sung
        • Lau HuiJew
      • Acts >
        • Portraiture
        • A Slice of Space Time
        • Box of Installation of Lights
        • Radio Misreading
        • Grid of Destinies
        • Shelter
        • Anatomy of Pain
        • Tensigrity of Ego
        • Of Prisons and Walls
        • Forest of Nails
        • Curtain of Fears
        • Dissolution of the Ego
        • If it's Ain't Broken it's Ain't Worth Mending
        • Flight of Freedom
        • Cross of Complexity and Contradiction
        • interrogation
      • Stage >
        • Soap Box
      • Play
      • Approach
      • Galleria >
        • Martial Gallery
        • Drive Through Gallery
        • Clinique Gallery
        • Cafe Gallery
        • MACC Gallery
        • Haunted Gallery
        • Backpacker Hotel
        • Audio Bookshop Gallery
        • Funeral Parlour
        • Extreme Game Gallery
        • Play Ground
        • Wedding Gallery
        • Meditation Gallery
        • Water Tower
        • Photography Studio
        • Chapel Gallery
    • External Critique >
      • Discourse in Sem 06
      • Discourse in Sem 05 >
        • The Site - KB
        • The Rectilinear
        • The Paired Kidneys
        • The Boat
        • The Decepticon
        • The Curvature
      • EnviroDesign MasterClass 2015
    • Philosophy
    • Codes Regulations & Standards >
      • Building Codes
      • Fire Codes
      • QAQC & Building Inspection
      • Critics
  • Photo Essays
    • Shanghai
    • Siemreap
  • Contact

GRANTING OF EOT BY THE ARCHITECT UNILATERALLY

10/16/2019

0 Comments

 
Picture

Can the Architect unilaterally grant EOT to the contractor without any notice in accordance to the PAM Form 2006? 

Clause 23.1(a) of the said form stated that the giving of such notice shall be condition precedent to an entitlement of EOT. In contract law, a condition precedent is an event which must occur, unless its non-occurrence is excused, before performance under a contract becomes due. Sundra and Harban (2010) opined that the contractor shall on his own volition make such a notification as part of his implied obligation under the contract… citing NJ Carnell’s Causation and Delay in Construction Disputes as an early warning system to alert the parties to some occurrence of a potential EOT and to include such notice shall be a condition precedent, would mean that the employer is circumventing the effects of the ‘prevention principle’ as it benefitted its own breach, relying mostly on London Borough v Stanley Hugh Leach (1985) and Cabinets v Hili Morden Electronics Pty Ltd (1984). Undoubtedly, failure to serve a notice would result in the loss of rights by the contractor for EOT. Such position has been the original intent by the PAM Contract Drafting Committee (2010) citing Hudson’s Ed 4.132.

Reading in tandem with Clause 23.5(b), in assessing EOT the Architect may take into account and any other Relevant Events which in the Architect’s opinion will have an effect on the Contractor’s entitlement to an EOT, apparently this clause empowered the architect to make an opinion taking into account any other Relevant Events which may effect the contractor’s entitlement of EOT. Again, the opinion of the architect is limited to the provision set forth in Clause 23.8 with emphasise on Clause 23.8(x), any other ground of EOT expressly stated in the Contract. The PAM Contract Drafting Committee (2010) stated that the architect may consider any other relevant event which the contractor has not applied as a basis for his EOT. Sundra and Harban (2010) opined that the architect must nevertheless act reasonably and that the relevant event must be those stipulated in Clause 23.8 and no more, citing two Austrialian cases of Peninsular Balmain v Abigroup Contractors (2002) and Graymark Investment v Walter Construction (1999). Apparently, Clause 23.5(b) has been drafted to excuse the compliance of a notice as a condition precedent at the liberty of the architect, upholding the prevention principle that the defaulting party cannot benefits from its own breach.  

Reading in tandem with Clause 23.10, the Architect may … after CPC review and fix a completion date later than that previously fixed … upon reviewing a previous decision or otherwise and whether or not a Relevant Event has been specifically notified by the Contractor. The PAM Contract Drafting Committee (2010) view of this clause, the architect is empowered to review EOT previously granted after CPC, taking into consideration all relevant events that may have affected the completion date irrespective of whether or not the relevant event has been considered previously or has been notified by the contractor.
​
In conclusion, the architect has the power to unilaterally grant EOT to the contractor without any notice in accordance to PAM Form 2006, relying on Clause 23.5(b), to enable the architect, to uphold his opinion that the defaulting party cannot benefits from its own breach and Clause 23.10, to allow the architect a chance to make the non-obligatory final review of his own opinion with regard to the EOT previously granted. With these two clauses in placed, it would also mean that the specific performance of giving of such notice shall be condition precedent to an entitlement of EOT shall only be binding to the contractor as a procedural condition in his application for EOT to give early warning to the architect of the impending delay and not necessarily result in the loss of his rights for EOT and by extension, claims for loss and/or expense. 
0 Comments

    DYA+C

    Author

    DYA+C is set up by Ar. DAVID YEK TAK WAI to undertake resolution of commercial disputes through ARBITRATION and ADJUDICATION, specializing in CONSTRUCTION PAYMENT DISPUTES.

    This is an educational blog. We do not guarantee, confirm nor warrant the accuracy of the information and facts stated therein. Read at your own 'risk'.

    Archives

    December 2022
    November 2021
    October 2021
    September 2021
    May 2021
    April 2021
    March 2021
    January 2021
    December 2020
    November 2020
    October 2020
    September 2020
    June 2020
    May 2020
    April 2020
    October 2019
    September 2019
    August 2019
    April 2019
    December 2018

    Categories

    All
    AALCO
    Acific Associates V Baxter [1989]2AllER159
    ACP
    Act Of Criminal
    Ad Hoc Mediation
    Adjudication
    AIAC
    AIAC Form
    Arbitration
    Arbitration Conference 2018
    Arenson V Casson Beckman Rutley [1977]AC405
    Art 121 Federal Constitution
    Art7(ad)PAM2006
    Art.7 PAM 2006
    Bellefield Computer Services V E. Turner & Sons Ltd (No. 2) [2002]
    Bettini V Gye (1876)
    Bias
    Bills Of Quantities BQ
    Blakemores LDP (in Administration) V Scott And Others [2015]
    Board Of Architect Malaysia LAM
    Cadenvish Case UK
    Canary Wharf V. EMA [2019]
    Caparo Industries V Dickman [1990]
    Carillion Collapsed
    CCC
    Certifier
    CFO
    Chambers V Goldthorpe [1901]
    Chitty On Contracts
    CIArb
    CIDB
    CIDB Form
    CIMB Bank Bhd V Anthony Lawrence Bourke & Anor [2019]
    CIPAA
    Clause 1.4
    Clause 18
    Clause 2.0
    Clause 21.4
    Clause 23.10
    Clause 23.1(a)
    Clause 23.5(b)
    Clause 23.8(a)
    Clause 23.8(w)
    Clause 24.1(b)
    Clause 24.3(c)
    Clause 24.3(n)
    Clause 2.(a)
    Clause 3.1
    Clause 4.1
    Clause 4.3
    Clause 7.1
    Confidentiality
    Construction Law
    Contract Administration
    CPC
    Cubic Electronic Vs Mars Telecommunications
    Defect Liability
    Delay
    Disclosure
    Discrepancy Dwgs-Bills
    Dispute Clause
    Drawings
    Dysfunctional Arbitration Agreement
    EOT
    Evaluative Mediation
    Ezumi
    FIDIC Form
    Final Costs
    Fong Wan Reality V PJ Condominium S/B [2010]
    Force Majeure
    Fraudulent Misrepresentation
    Frustration
    Goh Teng Whoo & Anor V Ample Objectives
    Good-Faith
    Guan Aik Moh (KL) Sdn Bhd & Anor V Selangor Properties Bhd [2007]
    Hadley V Baxendale [1854]
    Halliburton V Chubb [2020]
    Haward And Others V Fawcetts (a Firm) [2006]
    HDA
    HGCRA
    Hong Kong Fir Shipping V Kawasaki Kisen [1962]
    IEM Form
    Immunity
    Impartiality
    Incorporation Of Societies
    Independence And Impartiality
    Infectious Diseases Act 1988
    Initial Costs
    Intan Payong Sdn Bhd V. Goh Saw Chan Sdn Bhd [2004]
    JKR Form
    KKM
    KLRCA
    Krell V Henry [1903]
    Li Ching Wing V Xuan Yi Xiong [2004]
    Limitation Act 1953
    Limitation (Amendment) Act 2018
    Liquidated Damages
    Lok Kok Beng V Loh Chiak Eong [2015] 7 CLJ 1008
    Long-Stop
    Loss & Expense
    Low & Associates) V Persatuan Kanak Kanak Spastik Selangor & Wilayah Persekutuan And Another Case [2021] MLJU 430
    Low & Associates) V Persatuan Kanak-Kanak Spastik Selangor & Wilayah Persekutuan And Another Case [2021] MLJU 430
    Masenang Sdn Bhd V Sabanilam Enterprise Sdn Bhd
    MBank (M) Bhd V Abdul Aziz Hassan & Ors [2010]
    MCO
    Mears V Costplan [2019] EWCA Civ 502
    MITI
    Mitigation
    MKN
    NEC Form
    Pacific Forest Industries Sdn Bhd V Lin Wen-Chih [2009]
    PAM
    PAM Advisory
    PAM Form
    PAM Mediation
    PAM-Mediation
    Party Autonomy
    Pathological Defects
    PCP V L3 [2019]1LNS1321
    Police Act 1967
    Postal Rule
    PPE
    Preliminaries
    Prolongation Costs
    Public Policy
    PWD Form
    Qimonda V Sediabena (2012)
    Recurrent Costs
    Renegotiation
    Retention-Money
    RIBA Form
    S.14 Malaysian Arbitration Act 2005
    S.15 – 16 Civil Law Act 1956 CLA
    S.22 Arbitration Act 2005
    S.57(2) CA 1950
    S.70(21)SBDA1974
    Saga Fire Engineering V Lee Yee Seng [2017]
    SBDA 1974
    Schedule Of Rates
    Seat
    Selvakumar Vs Thiagarajah
    Serving Of Notice
    Sharikat Ying Mui Sdn Bhd V Hoh Kiang Po [2015]
    SK M&E Bersekutu V Pembinaan Legenda Unggul (2019)
    Skyworld Development Sdn Bhd V. Zalam Corporation Sdn Bhd & Other Cases. [2019]
    Societies Act 1966
    SOPL
    Standard Form Of Building Contract
    Statute Of Limitation
    Sutcliffe V Thackrah [1974]
    Temporary Measures For Reducing The Impact Of Coronavirus Disease 2019 (COVID 19)
    Temporary Measures For Reducing The Impact Of Coronavirus Disease 2019 (COVID-19)
    The Ara Joint Management Body V Mammoth Land & Development Sdn Bhd [2017]
    Trust Law
    UBBL 1984
    UK's Limitation Act 1980
    Ultra Vires
    VP
    Warranty
    Working Days

    RSS Feed

Powered by Create your own unique website with customizable templates.
  • Home
  • About
    • Professional Registration
    • Qualifications
    • Engagements
    • Private Practice
    • SIF Fellows
  • Practice
    • Our Approach >
      • S:Scale [Artefacts]
      • M:Scale [Building]
      • L:Scale [Urban]
    • Large Projects >
      • Highrises >
        • SSM International School
        • JBio
        • UKIH
        • Vertigo Residency
        • Diorama
        • Resi-Hub
        • SunMed
        • Medini
        • Palmspring Damansara
        • Blink
      • Lowrises >
        • Data Center
        • Garden Homes
        • XIN
        • Albient
        • Hillcourt
    • Small Projects >
      • Rustic Raphsody
      • MCM >
        • Estate House
        • Uniform Annex
        • Kitchen Extension
        • Sixth Form Center
      • Putrajaya Boulevard >
        • LOO
        • BOO
        • DOO
        • 5 Elements Tower
      • Detached Houses >
        • Batu Residence
        • Malaqa Residence
        • ParkCity Residence
        • Sierramas Residence
      • Commercial >
        • Albion Club
        • QuanYuan
        • Nippon Go
    • Interior Designs >
      • Spartan Minimalism
      • Neo Retro
      • Reflective Modern
    • UBBL 1984
    • Newsletter
  • DYA + C
    • Our CV
    • Adjudication >
      • CIPAA Procedure >
        • Scope of CIPAA
    • Arbitration >
      • Appointment of Arbitrator >
        • Terms of Appointment >
          • Preliminary Meeting Agenda
      • PAM Arbitration Procedure
      • Arbitration Costs Breakdowns >
        • Drawdown
      • Award Writing Blog >
        • Expert Evidence in Arbitration
    • Mediation >
      • Appointment of Mediator
      • Mediation Process
      • Skill Set Lev 01 & 02
    • Expert Determination >
      • Expert Rules - PAM
      • Expert Determination Processes
    • Building Inspection Services
    • Courses & Training >
      • Contract Administration
    • ADR & Construction Law
  • Consultant
    • QuanYuan 泉緣 Story
    • Review
    • QuanYuan >
      • Why QuanYuan?
      • Modus Operandi
      • Consultancy Services
    • Our Lineage
    • Workshop >
      • Teacher's Profiles
      • Message
      • SanYuan 01 - Introduction
      • Community
      • Registration of Interest
    • QiMen DunJia 奇門遁甲 >
      • QMDJ - Shifting Palace
    • Audit & Cases >
      • Cases - REA Hotel
      • Cases - Childless Couple
      • Cases - Childless Couple 02
    • Yifengshui
    • Newsletter >
      • MBS FengShui Reinvestigated
    • FAQ
    • E-Store
  • Educator
    • Author I am...
    • Speaking Engagement >
      • International Contract
      • PAM cpd UNLIMITED 2.0
      • Arch Edu Practice Paper - 3Ds Pedagogy
    • Attempting Law School
    • Journey in USM(Arch) >
      • Thesis >
        • Site Analysis
        • Urban Design Approach
        • Sketch Design
        • Model Based Paradigm
        • Technical Studies
      • Studio 01
      • Studio 02
    • Discourse in Studio 6 >
      • Ideation
      • The Production Model >
        • The Actors
        • The Stage
        • Urban Mass
        • The Box
        • The Play
        • The Break
        • The Newsletter
        • The Document
        • The Presentation
    • d:KON 4 >
      • Actors >
        • Chua LiCheng
        • Ng KenHong
        • Sean Tan
        • Peggy Chai
        • Elliotte Teoh
        • Vincent Tow
        • TzeLer
        • Elaine
        • Ng SongChun
        • Carissa Foong
        • Ng WeiMun
        • Ng ChenYin
        • Nicol Ong
        • Adron Liang
        • Ivan Sung
        • Lau HuiJew
      • Acts >
        • Portraiture
        • A Slice of Space Time
        • Box of Installation of Lights
        • Radio Misreading
        • Grid of Destinies
        • Shelter
        • Anatomy of Pain
        • Tensigrity of Ego
        • Of Prisons and Walls
        • Forest of Nails
        • Curtain of Fears
        • Dissolution of the Ego
        • If it's Ain't Broken it's Ain't Worth Mending
        • Flight of Freedom
        • Cross of Complexity and Contradiction
        • interrogation
      • Stage >
        • Soap Box
      • Play
      • Approach
      • Galleria >
        • Martial Gallery
        • Drive Through Gallery
        • Clinique Gallery
        • Cafe Gallery
        • MACC Gallery
        • Haunted Gallery
        • Backpacker Hotel
        • Audio Bookshop Gallery
        • Funeral Parlour
        • Extreme Game Gallery
        • Play Ground
        • Wedding Gallery
        • Meditation Gallery
        • Water Tower
        • Photography Studio
        • Chapel Gallery
    • External Critique >
      • Discourse in Sem 06
      • Discourse in Sem 05 >
        • The Site - KB
        • The Rectilinear
        • The Paired Kidneys
        • The Boat
        • The Decepticon
        • The Curvature
      • EnviroDesign MasterClass 2015
    • Philosophy
    • Codes Regulations & Standards >
      • Building Codes
      • Fire Codes
      • QAQC & Building Inspection
      • Critics
  • Photo Essays
    • Shanghai
    • Siemreap
  • Contact