DAVIDYEK
  • Home
  • About
    • Professional Registration
    • Qualifications
    • Engagements
    • Private Practice
    • SIF Fellows
  • Practice
    • Our Approach >
      • S:Scale [Artefacts]
      • M:Scale [Building]
      • L:Scale [Urban]
    • Large Projects >
      • Highrises >
        • SSM International School
        • JBio
        • UKIH
        • Vertigo Residency
        • Diorama
        • Resi-Hub
        • SunMed
        • Medini
        • Palmspring Damansara
        • Blink
      • Lowrises >
        • Data Center
        • Garden Homes
        • XIN
        • Albient
        • Hillcourt
    • Small Projects >
      • Rustic Raphsody
      • MCM >
        • Estate House
        • Uniform Annex
        • Kitchen Extension
        • Sixth Form Center
      • Putrajaya Boulevard >
        • LOO
        • BOO
        • DOO
        • 5 Elements Tower
      • Detached Houses >
        • Batu Residence
        • Malaqa Residence
        • ParkCity Residence
        • Sierramas Residence
      • Commercial >
        • Albion Club
        • QuanYuan
        • Nippon Go
    • Interior Designs >
      • Spartan Minimalism
      • Neo Retro
      • Reflective Modern
    • UBBL 1984
    • Newsletter
  • DYA + C
    • Our CV
    • Adjudication >
      • CIPAA Procedure >
        • Scope of CIPAA
    • Arbitration >
      • Appointment of Arbitrator >
        • Terms of Appointment >
          • Preliminary Meeting Agenda
      • PAM Arbitration Procedure
      • Arbitration Costs Breakdowns >
        • Drawdown
      • Award Writing Blog >
        • Expert Evidence in Arbitration
    • Mediation >
      • Appointment of Mediator
      • Mediation Process
      • Skill Set Lev 01 & 02
    • Expert Determination >
      • Expert Rules - PAM
      • Expert Determination Processes
    • Building Inspection Services
    • Courses & Training >
      • Contract Administration
    • ADR & Construction Law
  • Consultant
    • QuanYuan 泉緣 Story
    • Review
    • QuanYuan >
      • Why QuanYuan?
      • Modus Operandi
      • Consultancy Services
    • Our Lineage
    • Workshop >
      • Teacher's Profiles
      • Message
      • SanYuan 01 - Introduction
      • Community
      • Registration of Interest
    • QiMen DunJia 奇門遁甲 >
      • QMDJ - Shifting Palace
    • Audit & Cases >
      • Cases - REA Hotel
      • Cases - Childless Couple
      • Cases - Childless Couple 02
    • Yifengshui
    • Newsletter >
      • MBS FengShui Reinvestigated
    • FAQ
    • E-Store
  • Educator
    • Author I am...
    • Speaking Engagement >
      • International Contract
      • PAM cpd UNLIMITED 2.0
      • Arch Edu Practice Paper - 3Ds Pedagogy
    • Attempting Law School
    • Journey in USM(Arch) >
      • Thesis >
        • Site Analysis
        • Urban Design Approach
        • Sketch Design
        • Model Based Paradigm
        • Technical Studies
      • Studio 01
      • Studio 02
    • Discourse in Studio 6 >
      • Ideation
      • The Production Model >
        • The Actors
        • The Stage
        • Urban Mass
        • The Box
        • The Play
        • The Break
        • The Newsletter
        • The Document
        • The Presentation
    • d:KON 4 >
      • Actors >
        • Chua LiCheng
        • Ng KenHong
        • Sean Tan
        • Peggy Chai
        • Elliotte Teoh
        • Vincent Tow
        • TzeLer
        • Elaine
        • Ng SongChun
        • Carissa Foong
        • Ng WeiMun
        • Ng ChenYin
        • Nicol Ong
        • Adron Liang
        • Ivan Sung
        • Lau HuiJew
      • Acts >
        • Portraiture
        • A Slice of Space Time
        • Box of Installation of Lights
        • Radio Misreading
        • Grid of Destinies
        • Shelter
        • Anatomy of Pain
        • Tensigrity of Ego
        • Of Prisons and Walls
        • Forest of Nails
        • Curtain of Fears
        • Dissolution of the Ego
        • If it's Ain't Broken it's Ain't Worth Mending
        • Flight of Freedom
        • Cross of Complexity and Contradiction
        • interrogation
      • Stage >
        • Soap Box
      • Play
      • Approach
      • Galleria >
        • Martial Gallery
        • Drive Through Gallery
        • Clinique Gallery
        • Cafe Gallery
        • MACC Gallery
        • Haunted Gallery
        • Backpacker Hotel
        • Audio Bookshop Gallery
        • Funeral Parlour
        • Extreme Game Gallery
        • Play Ground
        • Wedding Gallery
        • Meditation Gallery
        • Water Tower
        • Photography Studio
        • Chapel Gallery
    • External Critique >
      • Discourse in Sem 06
      • Discourse in Sem 05 >
        • The Site - KB
        • The Rectilinear
        • The Paired Kidneys
        • The Boat
        • The Decepticon
        • The Curvature
      • EnviroDesign MasterClass 2015
    • Philosophy
    • Codes Regulations & Standards >
      • Building Codes
      • Fire Codes
      • QAQC & Building Inspection
      • Critics
  • Photo Essays
    • Shanghai
    • Siemreap
  • Contact

MCO 04 – NEW NORMALITY BITES

5/1/2020

0 Comments

 
Picture

POSTCRIPT:

Interesting enough the conundrum of MCO has been given another, "garnishes of the stale plate" as the stakeholders are all 'surfing in the dark', where more questions are remained unanswered. Although something interesting I noticed from the webinar, 'Kisah Benar', the lawyers are exploring unchartered territory relying on the following logic:

Foremost,  cl.11.1, PAM 2018 requires "[Variation] means the alteration or modification [...]" and with regards to cl.11.1(d), "Any changes to the provision of the contract" [may also take into consideration the saving effects of the COVID ACT]; with regards to, cl.11.1(d)(i), "Any limitation of working hours", by token imposed upon by the MCO, compliance to SOP, FMCO and the sorts. Cl.11.7, "[Variation] has caused [...] contractor to incur additional expenses"; cl.11.7(a), "[Written] Notice to the Architect", and vested upon the Architect to ascertain accordingly. 

Secondly, this move away from the reliance on cl.4.2, "inconsistencies between the [Documents] and any laws regulation [...] give to the Architect a written notice"; on the pretext that the MCO, FMCO and compliance to SOP, is a changes in the law that has not been contemplated by the parties before, thus the 'discrepancies'; although lawyers find difficulty to reconcile this, owing to the fact that most lacked the site-experiences. 

Thirdly, the 'tipping point' between cl.11.7 and cl.4.2, is cl.11.7 require the Architect's Instruction as condition precedent and cl.4.2, has a 'deeming-effect', in absence of an AI. So, the question is will the Architect stands to lean towards the contractor to issue an AI to invoke cl.11.7? Highly unlikely ...

​MCO 04 – NEW NORMALITY BITES

Welcome to MCO 04 from 28.04.2020 to 12.05.2020. Having gone through the 3 phases everybody in the construction industries are looking at the ‘crystal ball’ to see ‘when it is going to end’, what is the ‘exit plan’ and more importantly, how to face the ‘new normal’. While some is in ‘consolidation’, ‘downsizing’, ‘closing shops and claim frustration’ or ‘forge ahead’, it is no longer a question of ‘extension of time’, but who is going to pay for the ‘extra costs’ of ‘moving ahead’, while some contract provided the provision of ‘mitigation of delay’ vested upon the contractor to ‘forge ahead’, at whose costs? That is a question…

The PAM Form 2006 provided at least 4 routes to go about, or it could be more, but let’s look at this 4 possible ways to maneuver the delirium of post-MCO ‘new normal’…

Foremost, the force majeure exit plan. Everyone is chanting force majeure, from the President of PAM to our minister. What is this force majeure? Unlike other standard forms of contract, the PAM2006 has been very explicitly defined force majeure to include epidemic[1]. A question may arise, what is the different between an epidemic and a pandemic. Covid-19 was declared a pandemic. Does it automatically qualify as a force majeure? If the minister says so, where is the ‘gazette’? Sorry, forgot, the parliament too is in ‘lock down’. So, it remains a theoretical question at the moment. Having said that, based on an advisory from the President of PAM to the Architect to render and only to ‘recognize’ any EOT application under this force majeure while omitting the rest of the ‘other possibilities’ in the absent of a ‘national gazette’ automatically classifying the MCO as a force majeure, regardless of how the ‘contract is formed’, would any rational mind construe such as being ‘just’? Notwithstanding that the next, possible event to take place is to instruct the contractor to ‘mitigate delay’ by applying to MITI to resume work during MCO. The next logical question is, who is going to pay for the extra-costs and expenses incurred to fulfill MITI’s ‘strict conditions’, having to note that a force majeure is a ‘neutral event’ not due to anyone’s fault yet, the contractor may have to absorbed all costs and risk arising from its action of ‘mitigating delay’ to work during MCO, for all purpose that the contractor is still liable to indemnify against the employer for any breach[2].

Second, the ‘changes to the law’ exit plan. There are possibility to rely on a change in the ‘law governing the construction industry’ as an exit plan to forge ahead with a view to be compensated[3] for loss and or expenses arising from this ‘changes to the law’.[4] Reminded by the fact that MCO was invoked under two existing legislation namely the Prevention and Control of Infectious Diseases Act 1988 and the Police Act 1967, where is the ‘changes to the law’? The respective Local Authorities PBT is still relying on the power and jurisdiction under the Street Drainage and Building Act 1974 for administration of the MCO. Unless otherwise via an Act of Parliament such as those mirrored against our neighboring Singapore’s the COVID-19 Act 2020, such can be construed as ‘changes to the law’ exit plan with a view to be compensated for loss and or expenses besides EOT.

Third, the ‘Stop Work Order’ Architect’s Instruction AI exit plan. This is a ‘novel idea’ that some Architect friends actually say, “[…] you need a ‘spine’ or alternatively, a ‘steel ball’ to issue such an AI for such, you may not get another project from your Client, post-MCO” Acknowledging the fact that by virtue of this simple AI, it has placed upon the shoulder of the Architect that arising from this act, alone, he has caused the contractor to ‘stop work’[5], ‘discontinue work’ or ‘temporary halt work’ on site, for reasons only best known to the architects, thus the notion of the ‘satisfaction of the architect’. Under such circumstances, the PAM2006 form allows the contractor to be compensated[6] with loss and or expenses together with the relevant EOT, subject otherwise to any ‘mitigation of delay’ required by the contractor. At least such appear to be ‘fair’ to both parties and the most ‘noble act’ to have been performed by the Architect, without ‘fear and favor’, avoiding dispute in any manner foreseeable. Sorry, how many Architects actually do so?  

Finally, the ‘Government’s Stop Work Order’ exit plan. Having to ‘toe the line’ some Architects may be ‘smart enough’ to circumvent the ‘conundrum’ by issuing a rather ‘vague’ AI such as “You are herewith instructed to comply with the Government of Malaysia’s Order for MCO” In other words, the Architect has instructed the contractor to ‘follow government’s instruction’ not its ‘instruction to stop work’, brilliant! For obvious reasons, now the contractor has been placed in a ‘doubtful situation’ as can such AI be construed as a ‘stop work order’ enabling them to claim EOT and ultimately, loss and or expenses? It appears to be that the contractor is ‘statutory bound’ to comply with the government’s instruction and thus entirely and mandatory ‘self voluntarily’ that has nothing whatsoever to do with the ‘employer or its agent’. Another facet is to look at arising from the MCO, the contractor cannot carry out its work and not the force majeure arising from the pandemic as the MCO is the causa causans to the course of the ‘damages’ in the entire ‘matrix of causation’. However, it is interesting to note that the PAM2006 allows for loss and or expenses arising from a delay due to a ‘stop work order’ from the government, subject otherwise that such is due to the ‘omission by the employer or its agent’[7]. Having said that, the ‘burden of proof’ falls squarely upon the shoulder of the contractor and the ‘sufficient of proof’ is on balance that the Architect has ‘failed to discharge’ its duty, thus the omission. Voila! Under the ‘strict liability rule’ and having a ‘close proximity’ in terms of reasonable ‘duty of care’ for the Architect towards the contractor, it is easily for the contractor just to mount a claim that the architect ought to have issue an AI for ‘stop work’ but it didn’t thus the omission of a reasonable ‘duty of care’ that has violated their rights under the contract.       

When the dust settles, we are able to see more clearly and rationally the entire spectrum of the effects of the MCO towards the continuity of work in the ‘new normal’ society. The legal construct of the ‘standard forms’ may have been ‘blinded’ by so many possibilities that has not been taken into consideration when the parties sealed the contract. The best possible way is a call to the government, instead of reliance on the obscure version of force majeure that only the ‘Frenchman’ knows what it truly meant, to pass an Act of Parliament mirrored  the Singapore’s COVID-19 Act 2020 and ‘ctr-alt-del’ any ‘contractual omissions’ for a ‘level playing field’ for a ‘new normal’ future.
​
Having wrote these as a personal reflection or opinion, not as a ‘lawyer’ or a legal counsel, as disclaimer, never take this writing of mine, to be your ‘legal advice’. You should seek appropriate ‘legal advice’ for your own situation. I am not liable for the accuracy of facts and representation on this writing.        

--------------------------------------------

[1] Art7(ad)PAM2006
[2] Cl.18.PAM2006
[3] Cl.4.3PAM2006
[4] Cl.4.1.PAM2006
[5] Cl.21.4.PAM2006
[6] Cl.24.3(c)PAM2006, “Compliance to a written AI in regard to the postponement […] to be executed under Cl21.4”
[7] Cl.24.3(n)PAM2006, “[…] provided always the same is due to negligence or omission on part of the employer […]”
0 Comments

DISPUTE AVOIDANCE DURING MCO – WHAT ARCHITECT CAN OR CANNOT DO?

4/5/2020

1 Comment

 
Picture

DISPUTE AVOIDANCE DURING MCO – WHAT ARCHITECT CAN OR CANNOT DO?

The first line of dispute avoidance is and has always been vested upon the shoulder of the ‘contract administrator’, by default such as so provided in the PAM form of building contract, the architect. The Movement Control Order MCO, announced by the government, now entered the 2nd extended weeks had been very challenging to architects. Issuing too much instructions to the contractor may either denying or allowing them to claim for unnecessary ‘loss and expenses’ with regards to having work ‘in remote’. Issuing too little instruction, may eventually deemed to be ‘not administering the contract’ with the duty of care expected from a contract administrator. So, the question is ‘how much’ instruction suffice for this instances of the MCO?

The first instruction is ‘necessary’ to put everyone in the project to ‘unambiguously’ recognize that the work on site has been ‘halted’. This instruction is meant to be a ‘stop work order’, as some architect may consciously wanted to avoid using this term that will eventually bring about the repercussion of ‘loss and expenses’ claim by the contractor and not looking too ‘impressive’ by the employer, who in the first instance, commissioned the architect. Yet, the architect has a ‘fiduciary duty’ to discharge impartially to the parties in the construction contract and ‘being ambiguous’ may not appear to be just in accordance to its ‘quasi-arbitral’ role, risked being sued by the parties in the contract. It is very common for architect to be sued these days for whatever reasons…

In the same instruction, it is ‘highly recommended’ for the architect to instruct the contractor to put in ‘mitigation effort’ foremost, to secure the site. How about ‘avoiding delay’? How do you wish the contractor to avoid delay, when it is foremost not his fault for this MCO? ‘Mitigating delay’ in such instances may come with a ‘cost’ and ‘unsuspecting’ architect may eventually issue the second instruction ordering ‘virtual-site meeting’ as though, ‘work carried on as usual’. In the said virtual meeting, other instructions may set in such as ‘issuance of further detailing’, request for ‘mock up’ approval, materials approval and all sort of things warranted the contractor’s ‘extra effort and equipment’ to provide and to facilitate. When reality sets in after the MCO, with the contractor issuing its ‘loss and expenses’ claim, the architect will further instruct the QS to evaluate and the very common answer as expected, ‘… it is not in the contract, the contractor cannot claim’. As it is, there appear to be a ‘dispute’ arising from an ‘instruction to avoid delay’, the pertinent question is, at whose fault? Employer or the architect? Mitigation of delay now becomes ‘mitigation to accelerate’?

In some contract, a provision maybe allowed for the architect to instruct for a ‘revise work programme’ taking into account the foreseeable delay arising from the MCO. Is it sufficed for the architect to immediately issue a 14 days Extension of Time EOT and reject the contractor’s application for EOT beyond the ‘gazetted’ MCO? Just wonder, if the construction work is like any other manufacturing work where one can have a ‘start button’ to press and everything works like clockwork after a ‘stop work’, therefore the 14 days Extension of Time EOT is sufficient? You may be looking for another ‘dispute’ on this matter. Having said that, with the MCO extended, will the architect has the obligation to issue the second instruction for ‘stop work order’?

It is interesting to note, if the architect would be at liberty to pronounce that the MCO is indeed a ‘force majeure’, so provided in the contract, if any and the contractor has no other means to request for EOT, other than relying on this ‘contributing event of delay’. Looking from the ‘factual matrix’, the situation of Covid19 has warranted the government to declare a MCO, under the Prevention and Control of Infectious Diseases Act 1988 and the Police Act 1967. Arising from such MCO, construction industries were not listed as ‘essential’ thus work on site is deemed to have been ‘delayed’ due to the ‘order’, as in the MCO, or the ‘force majeure’ event, or Covid19? Which ‘contributing event’ is to be considered the ‘causa causans’ to the ‘damages’ incurred? Having said that, do you think the contractor has ‘no right’ to claim for ‘loss and expenses’ due to a ‘neutral event’?

‘Force majeure’, having its root in the ‘civil law’ jurisdiction has not been given a clear definition in the ‘common law’. Chitty on Contracts suggested “it is trite that a party relying upon a force majeure clause must prove the facts bringing the case within the clause. He must therefore prove the occurrence of one of the events referred to in the clause and that he has been prevented, hindered or delayed, as that case may be from performing the contract by reason of the event. He must further prove that his nonperformance was due to circumstances beyond his control and that there were no reasonable steps that he could have taken to avoid or mitigate the event or its consequence”[i] (emphasis added).

Although it is not a statutory right in Malaysia, the PAM 2006 form, in its attempt to clarify, has provided that “any circumstances beyond the control of the contractor caused by terrorist acts, governmental or regulatory action, epidemics or natural disasters” [ii]. The question, now is, relying on both the provision in the PAM form and the pronouncement by the President of PAM via its advisory[iii], do the contractor required to proof to be excused of its obligation under the contract so provided as in Intan Payong Sdn Bhd V. Goh Saw Chan Sdn Bhd [2004][iv]?  If so, can the contractor claimed for ‘loss and expenses’, failing which the contractor has the right to seek compensation in the court of law, outside the construe of the ‘neutral event’ so provided in the contract?

The Federal Court held that “the court is not empowered to improve upon the instrument which it is called upon to construct. Further, it is an established principle of law that a party relying upon a force majeure clause must prove the facts bringing the case within the clause”, as in CIMB Bank Bhd v Anthony Lawrence Bourke & Anor [2019][v]. Apparently, PAM may construed to have taken the role of the court or the party of the contract, to proclaim ‘force majeure’ and guided by the ruling of Intan Payong, the contractor may very well unlikely to be successful to claim ‘loss and expenses’ under ‘force majeure’.

By limiting the party in the contract to mount a claim under the proclamation of ‘force majeure’ due to its effect of ‘neutral event’, so provided by the advisory, the architect may choose to advise the party to adopt such advice with discretion and caution as a mean of avoiding dispute. Having said that, it is unadvisable for the architect to issue instruction with ‘force majeure’ prescribed, without a proper understanding of such term and its repercussion that may be brought against the parties.    

As to the question of termination under ‘frustration’ arising from the non-performance due to ‘force majeure’, the general accepted legal principle was that if a provision has been allowed in the contract for ‘determination of the contractor’s employment’ due to ‘force majeure’ reason, the contractor has to invoke such provision to determine its contract, otherwise the s.57(2) CA 1950 may be relied upon for termination and s.15 – 16 Civil Law Act 1956 CLA, provided the parties with compensation given for the purposes of the performance or partial performance of the contract.

Authorities as in Pacific Forest Industries Sdn Bhd v Lin Wen-Chih [2009][vi], provided that a contract cannot simply be ‘frustrated’, ‘merely because it becomes difficult to perform’. The Malaysian position as per Guan Aik Moh (KL) Sdn Bhd & Anor v Selangor Properties Bhd [2007][vii] provided the test of ‘termination of contract’ due to frustration but since PAM form has provided for ‘determination of the contractor’s employment’, contractor may not ‘simply’ rely on frustration to terminate under his common law provision.

Care has to be taken with regard to the MCO has resulted in the contractual obligation being made ‘radically different’ from what has been undertaken, and that it would be ‘commercially unjustifiable’ to enforce it. What is such ‘radically different’ that it would be ‘commercially unjustifiable’ to enforce it by the contractor warrant a termination? One month plus of ‘loss and expenses’ not being recognized by the architect or arising from the instruction of the architect, the contractor suffered further ‘unrecognizable loss and expenses’?

The situation here in the construction industries cannot rely upon the classical case as in Krell v Henry [1903][viii] where “an agreement for rental of a flat for two days for the purpose of watching the coronation procession was frustrated in purpose due to the postponement of the coronation”. 

Even the HongKong case as in Li Ching Wing v Xuan Yi Xiong [2004][ix] where 10 days isolation order due to the SARS outbreak was construed as ‘insignificant a period’ mirrored against the overall 2 years fixed term period of the tenancy. The 1 month plus of ‘loss and expenses’ due to MCO, in this context, may rolled into a ‘huge quantum’ in ‘unrecognizable loss and expenses’.

Even in the recent UK case of Canary Wharf v. EMA [2019][x], whether a lease held by the European Medicine Agency EMA on a premise in London used as the headquarters is likely to be frustrated as a result of Brexit? The court held that since the effect of frustration is to ‘kill the contract’, the doctrine must not be lightly invoked and must be kept within very narrow limits. It will be very unlikely for the contractor to be successful to ‘kill the contract’ due to the MCO. Such we shall witness in the Malaysian court this very near future.

As the stakeholders in the construction industries generally held on the ‘acceptable common approach’ pertaining to the legal aspect of ‘force majeure’ and ‘frustration’, the Malaysian courts may provide totally ‘unexpected’ judgement, given every contractual scenarios may differed from one another. Therefore, care has to be given by the architect to avoid any dispute from arising between the parties as any ‘unconsidered’ instruction given may, not only increased the risks between the parties, but also subject the architect to be sued for misconduct and non-impartial. Surprised that until today there is no ‘advisory’ issued by the Board of Architect Malaysia LAM, the ‘statutory body’ that is rightly to be seen issuing advisories to the architect in practice in Malaysia.

Having wrote these as a personal reflection or opinion, not as a ‘lawyer’ or a legal counsel, as disclaimer, never take this writing of mine, to be your ‘legal advice’. You should seek appropriate ‘legal advice’ for your own situation. I am not liable for the accuracy of facts and representation on this writing.  

----------------------------

[i] Bale H.G. (ed) Chitty on Contracts (28th Ed. Sweet & Maxwell Ltd 1999) vol.1, p.273 – 274.
[ii] Art.7
[iii]<http://pam.org.my/images/announcements/2020/PAM_Advisory_Note_Covid 19_MCO_18.3.2020.pdf>
[iv] 1 LNS 537
[v] 2 MLJ 1
[vi] 6 MLJ 293
[vii] 3 CLJ 695
[viii] 2 KB 740
[ix] 1 HKC 353
[x] EWHC 335
1 Comment

    DYA+C

    Author

    DYA+C is set up by Ar. DAVID YEK TAK WAI to undertake resolution of commercial disputes through ARBITRATION and ADJUDICATION, specializing in CONSTRUCTION PAYMENT DISPUTES.

    This is an educational blog. We do not guarantee, confirm nor warrant the accuracy of the information and facts stated therein. Read at your own 'risk'.

    Archives

    December 2022
    November 2021
    October 2021
    September 2021
    May 2021
    April 2021
    March 2021
    January 2021
    December 2020
    November 2020
    October 2020
    September 2020
    June 2020
    May 2020
    April 2020
    October 2019
    September 2019
    August 2019
    April 2019
    December 2018

    Categories

    All
    AALCO
    Acific Associates V Baxter [1989]2AllER159
    ACP
    Act Of Criminal
    Ad Hoc Mediation
    Adjudication
    AIAC
    AIAC Form
    Arbitration
    Arbitration Conference 2018
    Arenson V Casson Beckman Rutley [1977]AC405
    Art 121 Federal Constitution
    Art7(ad)PAM2006
    Art.7 PAM 2006
    Bellefield Computer Services V E. Turner & Sons Ltd (No. 2) [2002]
    Bettini V Gye (1876)
    Bias
    Bills Of Quantities BQ
    Blakemores LDP (in Administration) V Scott And Others [2015]
    Board Of Architect Malaysia LAM
    Cadenvish Case UK
    Canary Wharf V. EMA [2019]
    Caparo Industries V Dickman [1990]
    Carillion Collapsed
    CCC
    Certifier
    CFO
    Chambers V Goldthorpe [1901]
    Chitty On Contracts
    CIArb
    CIDB
    CIDB Form
    CIMB Bank Bhd V Anthony Lawrence Bourke & Anor [2019]
    CIPAA
    Clause 1.4
    Clause 18
    Clause 2.0
    Clause 21.4
    Clause 23.10
    Clause 23.1(a)
    Clause 23.5(b)
    Clause 23.8(a)
    Clause 23.8(w)
    Clause 24.1(b)
    Clause 24.3(c)
    Clause 24.3(n)
    Clause 2.(a)
    Clause 3.1
    Clause 4.1
    Clause 4.3
    Clause 7.1
    Confidentiality
    Construction Law
    Contract Administration
    CPC
    Cubic Electronic Vs Mars Telecommunications
    Defect Liability
    Delay
    Disclosure
    Discrepancy Dwgs-Bills
    Dispute Clause
    Drawings
    Dysfunctional Arbitration Agreement
    EOT
    Evaluative Mediation
    Ezumi
    FIDIC Form
    Final Costs
    Fong Wan Reality V PJ Condominium S/B [2010]
    Force Majeure
    Fraudulent Misrepresentation
    Frustration
    Goh Teng Whoo & Anor V Ample Objectives
    Good-Faith
    Guan Aik Moh (KL) Sdn Bhd & Anor V Selangor Properties Bhd [2007]
    Hadley V Baxendale [1854]
    Halliburton V Chubb [2020]
    Haward And Others V Fawcetts (a Firm) [2006]
    HDA
    HGCRA
    Hong Kong Fir Shipping V Kawasaki Kisen [1962]
    IEM Form
    Immunity
    Impartiality
    Incorporation Of Societies
    Independence And Impartiality
    Infectious Diseases Act 1988
    Initial Costs
    Intan Payong Sdn Bhd V. Goh Saw Chan Sdn Bhd [2004]
    JKR Form
    KKM
    KLRCA
    Krell V Henry [1903]
    Li Ching Wing V Xuan Yi Xiong [2004]
    Limitation Act 1953
    Limitation (Amendment) Act 2018
    Liquidated Damages
    Lok Kok Beng V Loh Chiak Eong [2015] 7 CLJ 1008
    Long-Stop
    Loss & Expense
    Low & Associates) V Persatuan Kanak Kanak Spastik Selangor & Wilayah Persekutuan And Another Case [2021] MLJU 430
    Low & Associates) V Persatuan Kanak-Kanak Spastik Selangor & Wilayah Persekutuan And Another Case [2021] MLJU 430
    Masenang Sdn Bhd V Sabanilam Enterprise Sdn Bhd
    MBank (M) Bhd V Abdul Aziz Hassan & Ors [2010]
    MCO
    Mears V Costplan [2019] EWCA Civ 502
    MITI
    Mitigation
    MKN
    NEC Form
    Pacific Forest Industries Sdn Bhd V Lin Wen-Chih [2009]
    PAM
    PAM Advisory
    PAM Form
    PAM Mediation
    PAM-Mediation
    Party Autonomy
    Pathological Defects
    PCP V L3 [2019]1LNS1321
    Police Act 1967
    Postal Rule
    PPE
    Preliminaries
    Prolongation Costs
    Public Policy
    PWD Form
    Qimonda V Sediabena (2012)
    Recurrent Costs
    Renegotiation
    Retention-Money
    RIBA Form
    S.14 Malaysian Arbitration Act 2005
    S.15 – 16 Civil Law Act 1956 CLA
    S.22 Arbitration Act 2005
    S.57(2) CA 1950
    S.70(21)SBDA1974
    Saga Fire Engineering V Lee Yee Seng [2017]
    SBDA 1974
    Schedule Of Rates
    Seat
    Selvakumar Vs Thiagarajah
    Serving Of Notice
    Sharikat Ying Mui Sdn Bhd V Hoh Kiang Po [2015]
    SK M&E Bersekutu V Pembinaan Legenda Unggul (2019)
    Skyworld Development Sdn Bhd V. Zalam Corporation Sdn Bhd & Other Cases. [2019]
    Societies Act 1966
    SOPL
    Standard Form Of Building Contract
    Statute Of Limitation
    Sutcliffe V Thackrah [1974]
    Temporary Measures For Reducing The Impact Of Coronavirus Disease 2019 (COVID 19)
    Temporary Measures For Reducing The Impact Of Coronavirus Disease 2019 (COVID-19)
    The Ara Joint Management Body V Mammoth Land & Development Sdn Bhd [2017]
    Trust Law
    UBBL 1984
    UK's Limitation Act 1980
    Ultra Vires
    VP
    Warranty
    Working Days

    RSS Feed

Powered by Create your own unique website with customizable templates.
  • Home
  • About
    • Professional Registration
    • Qualifications
    • Engagements
    • Private Practice
    • SIF Fellows
  • Practice
    • Our Approach >
      • S:Scale [Artefacts]
      • M:Scale [Building]
      • L:Scale [Urban]
    • Large Projects >
      • Highrises >
        • SSM International School
        • JBio
        • UKIH
        • Vertigo Residency
        • Diorama
        • Resi-Hub
        • SunMed
        • Medini
        • Palmspring Damansara
        • Blink
      • Lowrises >
        • Data Center
        • Garden Homes
        • XIN
        • Albient
        • Hillcourt
    • Small Projects >
      • Rustic Raphsody
      • MCM >
        • Estate House
        • Uniform Annex
        • Kitchen Extension
        • Sixth Form Center
      • Putrajaya Boulevard >
        • LOO
        • BOO
        • DOO
        • 5 Elements Tower
      • Detached Houses >
        • Batu Residence
        • Malaqa Residence
        • ParkCity Residence
        • Sierramas Residence
      • Commercial >
        • Albion Club
        • QuanYuan
        • Nippon Go
    • Interior Designs >
      • Spartan Minimalism
      • Neo Retro
      • Reflective Modern
    • UBBL 1984
    • Newsletter
  • DYA + C
    • Our CV
    • Adjudication >
      • CIPAA Procedure >
        • Scope of CIPAA
    • Arbitration >
      • Appointment of Arbitrator >
        • Terms of Appointment >
          • Preliminary Meeting Agenda
      • PAM Arbitration Procedure
      • Arbitration Costs Breakdowns >
        • Drawdown
      • Award Writing Blog >
        • Expert Evidence in Arbitration
    • Mediation >
      • Appointment of Mediator
      • Mediation Process
      • Skill Set Lev 01 & 02
    • Expert Determination >
      • Expert Rules - PAM
      • Expert Determination Processes
    • Building Inspection Services
    • Courses & Training >
      • Contract Administration
    • ADR & Construction Law
  • Consultant
    • QuanYuan 泉緣 Story
    • Review
    • QuanYuan >
      • Why QuanYuan?
      • Modus Operandi
      • Consultancy Services
    • Our Lineage
    • Workshop >
      • Teacher's Profiles
      • Message
      • SanYuan 01 - Introduction
      • Community
      • Registration of Interest
    • QiMen DunJia 奇門遁甲 >
      • QMDJ - Shifting Palace
    • Audit & Cases >
      • Cases - REA Hotel
      • Cases - Childless Couple
      • Cases - Childless Couple 02
    • Yifengshui
    • Newsletter >
      • MBS FengShui Reinvestigated
    • FAQ
    • E-Store
  • Educator
    • Author I am...
    • Speaking Engagement >
      • International Contract
      • PAM cpd UNLIMITED 2.0
      • Arch Edu Practice Paper - 3Ds Pedagogy
    • Attempting Law School
    • Journey in USM(Arch) >
      • Thesis >
        • Site Analysis
        • Urban Design Approach
        • Sketch Design
        • Model Based Paradigm
        • Technical Studies
      • Studio 01
      • Studio 02
    • Discourse in Studio 6 >
      • Ideation
      • The Production Model >
        • The Actors
        • The Stage
        • Urban Mass
        • The Box
        • The Play
        • The Break
        • The Newsletter
        • The Document
        • The Presentation
    • d:KON 4 >
      • Actors >
        • Chua LiCheng
        • Ng KenHong
        • Sean Tan
        • Peggy Chai
        • Elliotte Teoh
        • Vincent Tow
        • TzeLer
        • Elaine
        • Ng SongChun
        • Carissa Foong
        • Ng WeiMun
        • Ng ChenYin
        • Nicol Ong
        • Adron Liang
        • Ivan Sung
        • Lau HuiJew
      • Acts >
        • Portraiture
        • A Slice of Space Time
        • Box of Installation of Lights
        • Radio Misreading
        • Grid of Destinies
        • Shelter
        • Anatomy of Pain
        • Tensigrity of Ego
        • Of Prisons and Walls
        • Forest of Nails
        • Curtain of Fears
        • Dissolution of the Ego
        • If it's Ain't Broken it's Ain't Worth Mending
        • Flight of Freedom
        • Cross of Complexity and Contradiction
        • interrogation
      • Stage >
        • Soap Box
      • Play
      • Approach
      • Galleria >
        • Martial Gallery
        • Drive Through Gallery
        • Clinique Gallery
        • Cafe Gallery
        • MACC Gallery
        • Haunted Gallery
        • Backpacker Hotel
        • Audio Bookshop Gallery
        • Funeral Parlour
        • Extreme Game Gallery
        • Play Ground
        • Wedding Gallery
        • Meditation Gallery
        • Water Tower
        • Photography Studio
        • Chapel Gallery
    • External Critique >
      • Discourse in Sem 06
      • Discourse in Sem 05 >
        • The Site - KB
        • The Rectilinear
        • The Paired Kidneys
        • The Boat
        • The Decepticon
        • The Curvature
      • EnviroDesign MasterClass 2015
    • Philosophy
    • Codes Regulations & Standards >
      • Building Codes
      • Fire Codes
      • QAQC & Building Inspection
      • Critics
  • Photo Essays
    • Shanghai
    • Siemreap
  • Contact